Page 6 October 1, 2020
PUBLIC NOTICES
NOTICE OF PUBLIC SALE OF GOODS
TO SATISFY LIEN AUCTION LOCATION:
13020 YUKON AVE. BLDG. Q,
HAWTHORNE, CA. 90250
In accordance with the provisions of the
California Commercial Code, Sections 7201-
7210, notice is hereby given that on Saturday,
October 10, 2020 at the hour of 10:00 am of
said date, at 13020 Yukon Ave. Bldg. Q, City
of Hawthorne, County of Los Angeles, State of
CA, the undersigned will sell at public auction
for cash, in lawful money of the United States,
the articles hereinafter described, belonging
to, or deposited with, the undersigned by the
persons hereinafter named at Gentle Giant
Moving. Said goods are being held on the
accounts of: Jason Bell, Edgar Davis, Rema
DuPont, Stacy Holmes, Sue Pai Joffe, Edna
Milner, Jose Osio, Relativity Studios, Annette
Rubin, Andrew Stevens, Beth Singleton,
Evelyn Smuckler, Gila Soofer, Shauna Spellman,
Terri/Thom Washington, Craig Roessler/
Janis Mekalien and Fred Zax. All other goods
are described as household goods, furniture,
antiques, appliances, tools, misc goods, office
furniture, and articles of art, equipment, rugs,
sealed cartons and the unknown. The auction
will be made for the purpose of satisfying the lien
of the undersigned on said personal property
to the extent of the sum owed, together with
the cost of the sale. For information contact
Gentle Giant Moving. Terms: Cash only with
a 15% buyer's premium. Inspection at sale
time. Payment and removal day of sale. All
buyers will be required to wear a mask and
social distance while at this facility. Auction
conducted by American Auctioneers, Dan
Dotson & Associates (800) 838-SOLD, (909)
790-0433 or www.americanauctioneers.com
Bond #FS863-20-14.
/S/ Gentle Giant
9/24, 10/1/20
CNS-3400102#
Hawthorne Press Tribune Pub. 9/24, 10/1/20
HH-26907
PUBLISH
YOUR
PUBLIC
NOTICES
HERE
ABANDONMENTS:
$125.00
ABC NOTICES:
$125.00
DBA
(Fictitious Business Name)
$75.00
NAME CHANGE:
$200.00
Other type of notice? Contact us
and we can give you a price.
For DBA’s email us at:
dba@heraldpublications.com
NOTICE OF SUCCESSOR PETITION TO
ADMINISTER ESTATE OF:
NORVIE L. NEWBERRY
CASE NO. 17STPB11525
To all heirs, beneficiaries, creditors, contingent
creditors, and persons who may otherwise be
interested in the WILL or estate, or both of
NORVIE L. NEWBERRY.
A PETITION FOR PROBATE has been filed
by JOHNNY NEWBERRY in the Superior
Court of California, County of LOS ANGELES.
THE SUCCESSOR PETITION FOR PROBATE
requests that KEENAN BROWN. PFF
be appointed as personal representative to
administer the estate of the decedent.
THE PETITION requests the decedent's WILL
and codicils, if any, be admitted to probate.
The WILL and any codicils are available for
examination in the file kept by the court.
THE PETITION requests authority to administer
the estate under the Independent Administration
of Estates Act. (This authority will allow the personal
representative to take many actions without
obtaining court approval. Before taking certain
very important actions, however, the personal
representative will be required to give notice to
interested persons unless they have waived
notice or consented to the proposed action.)
The independent administration authority will
be granted unless an interested person files an
objection to the petition and shows good cause
why the court should not grant the authority.
A HEARING on the petition will be held in
this court as follows: 10/22/20 at 9:30AM in
Dept. 44 located at 111 N. HILL ST., LOS
ANGELES, CA 90012
Notice of Telephonic Hearing
Due to court closures, you may participate
telephonically by scheduling with CourtCall
at 1-888-882-6878. Please check the court's
website at www.lacourt.com for information
regarding closure to the public.
IF YOU OBJECT to the granting of the petition,
you should appear at the hearing and state
your objections or file written objections with the
court before the hearing. Your appearance may
be in person or by your attorney.
IF YOU ARE A CREDITOR or a contingent
creditor of the decedent, you must file your claim
with the court and mail a copy to the personal
representative appointed by the court within the
later of either (1) four months from the date of
first issuance of letters to a general personal
representative, as defined in section 58(b) of
the California Probate Code, or (2) 60 days
from the date of mailing or personal delivery
to you of a notice under section 9052 of the
California Probate Code.
Other California statutes and legal authority
may affect your rights as a creditor. You may
want to consult with an attorney knowledgeable
in California law.
YOU MAY EXAMINE the file kept by the
court. If you are a person interested in the
estate, you may file with the court a Request
for Special Notice (form DE-154) of the filing of
an inventory and appraisal of estate assets or of
any petition or account as provided in Probate
Code section 1250. A Request for Special
Notice form is available from the court clerk.
Attorney for Petitioner
SCOTT D. FISHER, ESQ. - SBN 128454,
SCOTT D. FISHER, A PROF. LAW CORP
9454 WILSHIRE BLVD., PENTHOUSE SUITE
BEVERLY HILLS CA 90212
9/17, 9/24, 10/1/20
CNS-3398257#
Inglewood Daily News Pub. 9/17, 9/24, 10/1/20
HI-26902
Order to Show Cause
for Change of Name
Case No. 20SMCP00286
Superior Court of California, County of LOS
ANGELES
Petition of: BRYSON KENDALL BANKS for
Change of Name
TO ALL INTERESTED PERSONS:
Petitioner BRYSON KENDALL BANKS filed
a petition with this court for a decree changing
names as follows:
BRYSON KENDALL BANKS to
NEGUS ISSA GOLD
The Court orders that all persons interested
in this matter appear before this court at the
hearing indicated below to show cause, if any,
why the petition for change of name should
not be granted. Any person objecting to the
name changes described above must file a
written objection that includes the reasons for
the objection at least two court days before
the matter is scheduled to be heard and must
appear at the hearing to show cause why the
petition should not be granted. If no written
objection is timely filed, the court may grant
the petition without a hearing.
Notice of Hearing:
Date: OCT. 30, 2020, Time: 8:30 AM., Dept.: K
The address of the court is:
1725 MAIN STREET
SANTA MONICA, CA 90401
A copy of this Order to Show Cause shall be
published at least once each week for four
successive weeks prior to the date set for hearing
on the petition in the following newspaper
of general circulation, printed in this county:
INGLEWOOD DAILY NEWS
Date: 8/24/2020
HON. LAWRENCE CHO
Judge of the Superior Court
Inglewood Daily News Pub. 9/17, 9/24,
10/1, 10/8/20
HI-26904
PUBLIC NOTICE
Notice is hereby by given, StorQuest Self
Storage will sell at public sale by competitive
bidding the personal property of:
- Green,Sharda
Property to be sold: misc. household goods,
furniture, tools, clothes, boxes, toys, electronics,
sporting goods, and personal content.
Auction Company: www.StorageTreasures.com.
The sale ends at 2:00 PM on October 9th,
2020 at the property where said property has
been stored and which is located at StorQuest
Self Storage 4959 W 147th St, Hawthorne,
CA 90250. Goods must be paid in cash and
removed at the time of sale. Sale is subject to
cancellation in the event of settlement between
owner and obligated party.
9/24, 10/1/20
CNS-3397745#
Hawthorne Press Tribune Pub. 9/24, 10/1/20
HH-26906
CITY OF INGLEWOOD
INVITATION TO SUBMIT BID
(Specifications and Conditions
Governing Bid Award)
Project Subject to Bid:
“SERVICE CENTER YARD ROOFING,
FY 2020-21”
BID No.: CB-21-01
The City of Inglewood invites and will receive bids
duly filed as provided herein for the furnishing
of labor and materials and/or the completion
of the above-designated project.
An informational meeting for interested
bidders will be conducted on Wednesday,
October 7, 2020, at 10:00 a.m. at the City
Service Center Yard, 232-250 W Beach Ave,
Inglewood, CA 90302. The meeting will begin
outside the main building. Attendees will
be required to wear a face mask.
Please call the Project Manager, Eloy Castillo/
Catrece Bragg, at (310) 412-5333, or email
at (ecastillo@cityofinglewood.org / cjbragg@
cityofinglewood.org ), should you require further
information.
Each bid, to be considered, must be delivered
to and received by the City Clerk no later
than 11:30 a.m. on Wednesday, October
14, 2020, at the Office of the City Clerk, First
Floor of Inglewood City Hall, One Manchester
Boulevard, Inglewood, CA, 90301.
Each bid shall be submitted and completed in
all particulars using the form entitled, “Bidder’s
Proposal and Statement”, attached hereto and
must be enclosed, together with the requisite
bid security, in a sealed envelope addressed to
the City Clerk with the designation of the project
“SERVICE CENTER YARD ROOFING, FY
2020-21” appearing thereon.
Each bid shall state the unit price of each
item if called for on the Bidder’s Proposal and
Statement form. In the event alternative bids
are called for in said form, each alternative bid
shall be completed.
Bids will be opened in public in the City Clerk’s
Office and will then and there be announced
to all persons present.
Specifications and other Bid Documents for the
above items are on file in the Public Works
Department and may be obtained upon request.
Each bid must be accompanied by a deposit in
the form of cash, a cashier’s or certified check
made payable to the City of Inglewood, or a
bid bond, for an amount of not less than ten
percent (10%) of the aggregate amount of the
bid, as a guarantee that the successful bidder
will, within the time specified, enter into an
agreement as provided in the Bid Document
and furnish bonds when required in the Special
Provisions: one for Faithful Performance in
the amount of the Contract Sum, and one
for Contractor’s Labor and Materials in the
amount of the Contract Sum.
The City Council reserves the right to reject any
or all bids and to waive any irregularities in any
bid, and to take bids under advisement for a
period not to exceed sixty (60) days from and
after the date bids are opened and announced.
Attention is directed to the provisions of Labor
Code § 1725.5: No contractor or subcontractor
may be listed on a bid proposal for a public
works project (submitted on or after March 1,
2015) unless registered with the Department
of Industrial Relations (with limited expectations
for this requirement for bid purposes only under
Labor Code Section 1771.1a). No contractor or
subcontractor may be awarded a contract for
public work on a public works project (awarded
on or after April 1, 2015) unless registered
with the Department of Industrial Relations.
All contractors and subcontractors must furnish
electronic certified payroll records to the Labor
Commissioner for all new projects awarded on
or after April 1, 2015. The Labor Commissioner
may excuse contractors and subcontractors on
a project that is under the jurisdiction of one of
the four legacy DIR-approved labor compliance
programs (Caltrans, City of Los Angeles, Los
Angeles Unified School District and County of
Sacramento) or that is covered by a qualified
project labor agreement. The project is subject
to compliance monitoring and enforcement by
the Department of Industrial Relations.
Attention is directed to the provisions of Sections
1777.5 and 1777.6 of the Labor Code
concerning the employment of apprentices
by the Contractor or any subcontractor under
them. The Contractor or any subcontractor
shall comply with the requirements of said
sections in the employment of apprentices.
Information relative to apprenticeship standards
and administration of the apprenticeship
program may be obtained from the Director
of Industrial Relations, San Francisco, CA, or
the Division of Apprenticeship Standards and
its branch offices.
Also, Amendments to Assembly Bill 219
became effective on July 1, 2016. The amendments
made the following changes to Labor
Code section 1720.9: a company hauling
or delivering ready-mix concrete for a public
works contract shall perform the following:
(1) Register as a public works contractor; (2)
Submit a certified copy of the payroll records
required by subdivision (a) of Section 1776 to
RFB-0124
CITY OF INGLEWOOD
INVITATION TO SUBMIT BIDS
(Specifications and Conditions Governing
Award)
The City of Inglewood invites and will receive
bids duly filed as provided herein for the
furnishing of qualified “JANITORIAL MAINTENANCE
SERVICES FOR VARIOUS CITY
OF INGLEWOOD PARKS FREESTANDING
RESTROOMS” as specified in this document.
Each bid shall be submitted and completed in
all particulars and must be enclosed in a sealed
envelope addressed to the City of Inglewood,
Office of the City Clerk, Inglewood City Hall
1st Floor, with the designation of the project
“JANITORIAL MAINTENANCE SERVICES
FOR VARIOUS CITY OF INGLEWOOD
PARKS FREESTANDING RESTROOMS”
appearing thereon.
A MANDATORY PRE-BID CONFERENCE
AND SITE WALK IS SCHEDULED FOR
10:00 A.M., ON FRIDAY, OCTOBER 9TH,
2020. PLEASE MEET AT INGLEWOOD CITY
HALL, 1st FLOOR INFORMATION BOOTH,
ONE MANCHESTER BLVD., INGLEWOOD,
CA 90301.
THIS MEETING IS MANDATORY AND
THOSE WHO SUBMIT BIDS WITHOUT
ATTENDING THE PRE-BID CONFERENCE
AND SITE WALK WILL BE DEEMED NONRESPONSIVE
AND THEIR BIDS WILL NOT
BE OPENED.
THERE IS A TEN (10) MINUTE GRACE PERIOD.
ANYONE ARRIVING AFTER 10:10 A.M.
WILL NOT BE ALLOWED TO PARTICIPATE
IN THIS BID PROCESS.
Bids will be opened in public, on October 21,
2020 AT 11:30 A.M. in the Office of the City
Clerk and will be announced then and there to
the party that engaged the company and to
the general contractor within five working days
after the employee has been paid, accompanied
by a written time record that shall be certified
by each driver for the performance of job duties;
and (3) Ready-mix concrete companies’
requirement to submit payroll online to DIR
using its electronic certified payroll reporting
system is temporarily on hold.
Notice is hereby given that the City Council
has ascertained the prevailing rates of per
diem wages in the locality in which the work
is to be done for each craft or type of workman
or mechanic needed to execute the
Contract in accordance with the provisions of
Section 1770, etc. seq. of the Labor Code;
said prevailing rates are on file in the Office
of the City Clerk and are incorporated herein
by reference. Copies shall be made available
to any interested party on request.
Attention is directed to the provisions of Public
Contract Code Section 10164 concerning
Contractor’s licensing laws. This Contract
requires a Class A Contractor’s License. In
addition, a City of Inglewood business license
will also be required.
The successful bidder must obtain, and maintain
current until completion of the Project, an
Inglewood City Business License.
This Notice is given by order of the City Administrator
of the City of Inglewood, California,
and is dated this 24th day of September, 2020.
Artie Fields, City Manager
City of Inglewood, California
Inglewood Daily News Pub. 9/24, 10/1/20
HI-26908
City of Inglewood, Los Angeles County,
California
Invitation to Submit Bid
(Specifications and Conditions Governing
Bid Award)
Project Subject to Bid: “Traffic Signal Safety
Improvements: La Brea Avenue at Hardy Street”
The City of Inglewood invites and will receive bids
duly filed as provided herein for the furnishing
of labor and materials and/or completing the
above-designated project.
A mandatory pre-bid meeting for interested
bidders will be conducted on October 8th at
9 am at the Public Works City Yard at 222
Beach Avenue, Inglewood, CA 90301.
Due to the current COVID-19 situation, the City
will use best practices to accommodate social
distance during the meeting. Bidders shall
attend with proper face mask/coverage and
follow local protocols and guidelines.
Contact Raquel Mendez, at rmendez@
cityofinglewood.org should you require further
information.
Each bid to be considered must be delivered
to and received by the City Clerk no later than
11:00 a.m. on October 21st, 2020 at the Office
of the City Clerk, Inglewood City Hall; One West
Manchester Boulevard, Inglewood, CA 90301.
Each bid shall be submitted and completed in
all particulars using the form entitled, “Bidder’s
Proposal and Statement” attached hereto and
must be enclosed, together with the requisite
bid security in a sealed envelope addressed to
the City Clerk with the designation of the project
“Traffic Signal Safety Improvements: La Brea
Avenue at Hardy Street” appearing thereon.
Each bid shall state the unit price of each
item if called for on the Bidder’s Proposal and
Statement form. In the event alternative bids
are called for in said form, each alternative bid
shall be completed.
Bids will be opened in public in the City Clerk’s
Office and will then and there be announced
to all persons present.
Specifications and other bid documents for the
above items are on file in the Public Works
Department and may be obtained upon request.
Each bid must be accompanied by a deposit in
the form of cash, a cashier’s or certified check
made payable to the City of Inglewood, or a
bid bond, for an amount of not less than ten
percent (10%) of the aggregate of the bid, as
a guarantee that the successful bidder will,
within the time specified, enter into an agreement
as provided in the bid document and
furnish bonds when required in the Special
Provisions; one for faithful performance in the
amount of the contract sum, and another for
contractor’s labor and materials in the amount
of the contract sum.
The City Council reserves the right to reject any
or all bids and to waive any irregularities in any
bid, and to take bids under advisement for a
period not to exceed sixty (60) days from and
after the date bids are opened and announced.
Attention is directed to the provisions of Labor
Code § 1725.5: No contractor or subcontractor
may be listed on a bid proposal for a public
works project (submitted on or after March 1,
2015) unless registered with the Department
of Industrial Relations (with limited exceptions
for this requirement for bid purposes only under
Labor Code Section 1771.1a). No contractor or
subcontractor may be awarded a contract for
public work on a public works project (awarded
on or after April 1, 2015) unless registered
with the Department of Industrial Relations.
All contractors and subcontractors must furnish
electronic certified payroll records to the Labor
Commissioner for all new projects awarded on
or after April 1, 2015. The Labor Commissioner
may excuse contractors and subcontractors on
a project that is under the jurisdiction of one of
the four legacy DIR approved labor compliance
programs (Caltrans, City of Los Angeles, Los
Angeles Unified School District and County of
Sacramento) or that is covered by a qualified
project labor agreement. This project is subject
to compliance monitoring and enforcement by
the Department of Industrial Relations.
Attention is directed to the provisions of Sections
1777.5 and 1777.6 of the California Labor Code
concerning the employment of apprentices
by the Contractor or any subcontractor under
them. The Contractor or any subcontractor shall
comply with the requirements of said sections
regarding the employment of apprentices.
Information relative to apprenticeship standards
and administration of the apprenticeship program
may be obtained from the Director of Industrial
Relations, San Francisco, California, or the
Division of Apprenticeship Standards and its
branch offices.
Notice is hereby given that the City Council
has ascertained the prevailing rates of per
diem wages in the locality in which the work
is to be done for each craft or type of workman
or mechanic needed to execute the
contract in accordance with the provisions
of Section 1770, et. seq. of the Labor Code;
said prevailing rates are on file in the Office of
the City Clerk and are incorporated herein by
reference. Copies shall be made available to
any interested party on request.
Attention is directed to the provisions of Public
Contract Code Section 10164 concerning
Contractor’s licensing laws. This contract
requires at least a valid California Contractor
License Class “A” License and/or “C10” Electrical
Contractor at the time of bid. In addition, a City
of Inglewood business license will be required.
The successful bidder must obtain and maintain
current until completion of the project an
Inglewood City Business License.
This notice is given by order of the Assistant
City Manager of the City of Inglewood,
California, and is dated this 1st day of
October 2020.
Louis Atwell, Assistant City Manager/ PW
Director
City of Inglewood, California
Inglewood Daily News Pub. 10/1, 10/8/20
HI-26912
NOTICE OF PETITION TO ADMINISTER
ESTATE OF:
AUGUSTINE GEOGHAGEN AKA AUGUSTINE
BARNETT GEOGHAGEN AKA
AUGUSTINE LAVONDA GEOGHAGEN
CASE NO. 20STPB05197
To all heirs, beneficiaries, creditors, contingent
creditors, and persons who may otherwise be
interested in the WILL or estate, or both of AUGUSTINE
GEOGHAGEN AKA AUGUSTINE
BARNETT GEOGHAGEN AKA AUGUSTINE
LAVONDA GEOGHAGEN.
A PETITION FOR PROBATE has been filed
by ETHEL GIBBINGS in the Superior Court of
California, County of LOS ANGELES.
THE PETITION FOR PROBATE requests that
ETHEL GIBBINGS be appointed as personal
representative to administer the estate of the
decedent.
THE PETITION requests the decedent's WILL
and codicils, if any, be admitted to probate.
The WILL and any codicils are available for
examination in the file kept by the court.
THE PETITION requests authority to administer
the estate under the Independent Administration
of Estates Act. (This authority will allow the personal
representative to take many actions without
obtaining court approval. Before taking certain
very important actions, however, the personal
representative will be required to give notice to
interested persons unless they have waived
notice or consented to the proposed action.)
The independent administration authority will
be granted unless an interested person files an
objection to the petition and shows good cause
why the court should not grant the authority.
A HEARING on the petition will be held in
this court as follows: 11/25/20 at 8:30AM in
Dept. 79 located at 111 N. HILL ST., LOS
ORDINANCE NO.: 20-16
AN ORDINANCE OF THE CITY COUNCIL
OF THE CITY OF INGLEWOOD,
CALIFORNIA AMENDING CHAPTER 2,
ARTICLE 7 (CITY FUNDS – BUDGETARY
PROCEDURES) AND ARTICLE
9 (CONDITIONS OF EMPLOYMENT);
AMENDING CHAPTER 8, ARTICLE 3
(PERMITS); AND AMENDING CHAPTER
10, ARTICLE 5 (CURBS, SIDEWALKS
AND PARKWAYS)
WHEREAS, the City of Inglewood is experiencing
rapid growth in the implementation
of the Hollywood Specific Plan, the opening
of the Sofi Stadium (and its retail, dining and
office space proposed within the complex), the
Metro Rail, the Fiber Optics project, the potential
construction of the Inglewood Basketball and
Entertainment Complex (IBEC – an arena for
the Clippers, National Basketball Association
team), and awarded access to over $350
million in transportation and grant funds to be
used to reduce greenhouse gas emissions in
the City of Inglewood; and
WHEREAS, the Inglewood Investment Committee
held a meeting on June 3, 2020, and
discussed the recent changes in economic
development for the City, and
WHEREAS, during the June 3rd Investment
Committee meeting, staff was directed to
update the Investment Policy and Procedures
to reflect the approvals of the Committee; and
WHEREAS, with new revenue opportunities
potentially created by this dynamic growth, it
is critically important that the person(s) with the
responsibility for investing the City’s Surplus
Funds and record keeping are familiar with
the City’s day-to-day operations; and
WHEREAS, California State Government Code
Section 53600 authorizes all governing bodies
of local agencies to invest Surplus Funds; and
WHEREAS, the Code also provides the
City Council with the authority to delegate its
investment duties; and
WHEREAS, the City is required to comply
with its City Charter, which also provides the
authority to the City Council to align certain City
duties with the appropriate City Department.
NOW, THEREFORE, THE CITY COUNCIL
OF THE CITY OF INGLEWOOD does
ordain as follows:
SECTION 1. Inglewood Municipal Code Section
2-246 is hereby amended to read as follows:
“Section 2-246. Bank Accounts.
Unless otherwise required by law, all monies
received by the City shall be deposited in one
account in such bank or banks as the City
Council shall direct or approve. Such transfer
as may be necessary shall be made between
banks by using checks made payable to the
“City of Inglewood Only.”
The Mayor shall name the bank or banks that
shall redeem warrants, signed by the proper
officer or officers, for claims or demands which
have previously been approved by the City
Council, and shall approve such agreements
with such banks as may be contemplated by law
in connection with the deposit of public monies.
SECTION 2. Inglewood Municipal Code Section
2-277.1 is hereby repealed.
The responsibility of General Auditor shall be and
is removed from the Office of the City Treasurer
and is placed in the Office of the City Clerk
pursuant to the Charter of the City of Inglewood,
Article XVI, Section 4.
The City Clerk shall act as General Auditor
of all municipal finances and shall at regular
intervals, at least once each month, submit a
written report and accounting of all receipts,
disbursements and fund balances, a copy
of which report shall be filed with the City
Council. Additionally, as the General Auditor,
the City Clerk, with the assistance of the
Finance Director, shall determine and report
whether the assets are being properly used,
fairly stated and accounted for, and whether
all liabilities and fund balances are fairly stated.
Nothing herein contained, however, shall be
construed, in such a manner as to dispense
with internal control procedures or the annual
all persons present. Specifications and other
bid documents for the above service are on
file in the Purchasing Division, and may be
obtained upon request.
The City Council reserves the right to waive
any irregularity in any bid, and to take bids
under advisement for a period not to exceed
sixty (60) days from and after the date bids
are opened and announced.
The following conditions and terms apply:
The City Council reserves the right to reject
any or all bids.
Attached are detailed specifications and conditions
for bid submission.
You must execute your contract within ten (10)
days after the City mails it. If the contract is not
executed within ten (10) days, the City reserves
the unilateral right to cancel it.
If any provision of the contract is violated, the
City, after suitable notice, may cancel the contract
and make arrangements to have the products
and or services supplied by others. Any extra
cost to the City will be paid by the bidder.
Bids may be obtained from the Purchasing
Division located on the 8th floor of City Hall,
or call (310) 412-5266.
All bids must be for specific amounts. Any
attempt to qualify prices with an ‘escalation
clause’ or any other method of making a price
variable, is unacceptable. Bids shall be valid
until sixty (60) days after the date the bids are
opened and announced.
The City reserves the right to add or subtract
quantities and/or services based on the unit
prices/unit lump sums so indicated as its
budgetary needs may require.
Date: October 1, 2020
David Esparza, CFO/Asst. City Manager
Inglewood Daily News Pub. 10/1, 10/8/20
HI-26913
ANGELES, CA 90012
IF YOU OBJECT to the granting of the petition,
you should appear at the hearing and state
your objections or file written objections with the
court before the hearing. Your appearance may
be in person or by your attorney.
IF YOU ARE A CREDITOR or a contingent
creditor of the decedent, you must file your claim
with the court and mail a copy to the personal
representative appointed by the court within the
later of either (1) four months from the date of
first issuance of letters to a general personal
representative, as defined in section 58(b) of
the California Probate Code, or (2) 60 days
from the date of mailing or personal delivery
to you of a notice under section 9052 of the
California Probate Code.
Other California statutes and legal authority
may affect your rights as a creditor. You may
want to consult with an attorney knowledgeable
in California law.
YOU MAY EXAMINE the file kept by the
court. If you are a person interested in the
estate, you may file with the court a Request
for Special Notice (form DE-154) of the filing of
an inventory and appraisal of estate assets or of
any petition or account as provided in Probate
Code section 1250. A Request for Special
Notice form is available from the court clerk.
Attorney for Petitioner
DOUGLAS C. SPLETTER - SBN 196277,
EDWARD W. GOODSON - SBN 181250,
REYNOLDS LAW, LLP
1411 OLIVER ROAD, SUITE 300
FAIRFIELD CA 94534-3425
10/1, 10/8, 10/15/20
CNS-3402259#
Inglewood Daily News Pub. 10/1, 10/8,
10/15/20
HI-26914
or special audits otherwise provided for in the
Charter of the City of Inglewood.
SECTION 3. Inglewood Municipal Code Section
8-27 is hereby amended to read as follows:
Section 8-27. Committee. Creation and
Membership.
There is hereby created and established a
committee, consisting of the Administrative
Officer, Public Works Director, Emergency
Services Manager, Economic and Community
Development Director, the Police Chief and
the Fire Chief, to be known as the “Permits
and Licenses Committee.” The City Clerk
shall be secretary of the Committee, and
designated Finance Department staff will serve
as support staff. .
SECTION 4. Inglewood Municipal Code Section
10-44 is hereby amended to read as follows:
Section 10-44. Bond Required.
The Economic and Community Development
Director shall deny final approval and
acceptance and shall refuse to allow final
public utility connections, to any such building
or dwelling unless curbs, gutters, sidewalks
and streets exist or are constructed, or unless
cash is deposited with the Finance Department
or a bond is deposited with the City Clerk to
guarantee their construction in a sum equal
to the estimated cost of construction of said
improvements as determined by the Public
Works Director.”
SECTION 5. If any section, subsection, sentence,
clause, phrase or word of this Ordinance
is for any reason held to be invalid by a court of
competent jurisdiction, such decision shall not
affect the validity of the remaining portions this
Ordinance. The City Council hereby declares
that it would have passed and adopted this
Ordinance, and each and all provisions thereof,
irrespective of the fact that one or more provisions
may be declared invalid.
SECTION 6. The City Clerk shall certify that
to the approval, passage and adoption of this
Ordinance by the City Council and shall cause
the same to be published in accordance with
the City Charter, and thirty days from the final
passage and adoption, this Ordinance shall
be in full force and effect.
INTRODUCED at a regular meeting of the
Inglewood City Council on _October 1, , 2020.
PASSED, APPROVED AND ADOPTED at a
regular meeting of the Inglewood City Council
on _October 1, 2020
CITY OF INGLEWOOD:
James T. Butts, Jr., Mayor
ATTEST:
Yvonne Horton, City Clerk
Inglewood Daily News Pub. 10/1/20
HI-26915