November 22, 2018 Page 7 Wiseburn from page 3 accordingly. It also provides classroom teachers access to screening data related to their students outcomes; works with grade-level teacher teams to review student data and leverage Districtadopted language arts materials; provides an intervention cycle to coincide with the learning circles at each site; and increases Wiseburn’s strategic intervention personnel to work with students within the school day, equitably supporting those in need of intervention. In 2017/18, the Cabrillo and Anza elementary schools saw the number of students rise. Since implementation of the secondary screeners, the District is now able to group students according to their needs and thoughtfully target specific reading foundational skills, Nitsos reported. “We can now identify student growth and ongoing challenges with precision and ensure that every child succeeds,” she emailed. The last day on the job for Director of Facilities Planning Vince Madsen was on Nov. 15. Silvers called losing Madsen, who had been with the District since 2013 and spearheaded the construction of the new Wiseburn High School, “such a huge loss.” In his final thoughts to the community, Madsen emailed, “I am extremely proud of the accomplishments in the development of the Wiseburn High School: Home of the Da Vinci Schools, as it is. The 13-acre site was really the only property available after more than a two-year search for a high school in the South Bay. The site came with a lot of unique challenges that we needed to work through and mitigate (with different regulatory entities), as well as local considerations with the City of El Segundo. I am very proud of my almost 18-year career working in the South Bay.” Meanwhile, the pool and gymnasium opening ceremony is now slated for Dec. 20, with the pool hopefully becoming operational in January. In Board member reports, President JoAnne Kaneda spoke of the “productive session” on Nov. 8, as well as the need to ensure and control traffic safety around area schools. “We will continue to monitor that,” she said. Action items included the approval of the “Apparent Best Value” for architectural consulting services with LPA Architects for the continued planning and preparation of the District’s long-range facilities master plan; and approval of new school construction projects, including additional hardwood gym flooring. During his comments Thursday evening, Silvers highlighted the work accomplished by Kevin Corrinet, ex-US Army Ranger, who has developed the very popular CrossFit program at Dana Middle School. He also mentioned that the new District websites debuted online on Thursday. “We have had a phenomenal start to the school year…Everyone deserves a little rest,” Silvers said. After the Board passed multiple action items, mainly regarding construction and personnel, Kaneda closed the one-hour meeting around 8 p.m. • Calendar of Events from page 3 W. Manchester Blvd., Call: 310-412-5380. THURSDAY, NOV 29 • Chess for All Ages, 4:30 PM., free, Crenshaw Imperial Branch Library, 11141 Crenshaw Blvd., Call: 310-412-5403. • Preschool Story Time, 1:00 PM., for ages 3-5 yrs. old, Crenshaw Imperial Branch Library, 11141 Crenshaw Blvd., Call: 310-412-5403. • Sip & Read Adult Book Club, 4:00 PM., free, Crenshaw Imperial Branch Library, 11141 Crenshaw Blvd., Call: 310-412-5403. • Adult Coloring, 4:00 PM., free, Inglewood Public Library, 101 W. Manchester Blvd., Call: 310-412-5380. • Family Movie, 4:00 PM., free, Inglewood Public Library, 101 W. Manchester Blvd., Call: 310-412-5380. • Measure the Wind, 4:00 PM. – 5:00 PM., ages 5-12, Hawthorne Library, 12700 Grevillea Ave., Hawthorne, Call: 310-679-8193. • PUBLIC NOTICES There is always something to be thankful for. - Mom Order to Show Cause for Change of Name Case No. 18TRCP00029 Superior Court of California, County of LOS ANGELES Petition of: PRIYA NARAN for Change of Name TO ALL INTERESTED PERSONS: Petitioner PRIYA NARAN filed a petition with this court for a decree changing names as follows: PRIYA NARAN to PRIYA PATEL NARAN The Court orders that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Notice of Hearing: Date: 1-25-19, Time: 8:30 AM., Dept.: M The address of the court is: 825 MAPLE AVENUE TORRANCE, CA 90503-5096 A copy of this Order to Show Cause shall be published at least once each week for four successive weeks prior to the date set for hearing on the petition in the following newspaper of general circulation, printed in this county: HAWTHORNE PRESS TRIBUNE Date: NOV. 5, 2018 ERIC C. TAYLOR Judge of the Superior Court Hawthorne Press Tribune Pub. 11/8, 11/15, 11/22, 11/29/18 HH-26245 NOTICE INVITING BIDS DISTRICT: HAWTHORNE SCHOOL DISTRICT PROJECT IDENTIFICATION: Roofing Projects PROJECT NO.: Bid Number M18-19-3 MANDATORY PRE-BIDDER’S CONFERENCE AND JOB WALK : November 28, 2018: 8:30 AM Sharp! Hawthorne School District 13021 S. Yukon Ave Hawthorne, CA 90250 DEADLINE FOR RFI’S: December 4, 2018; 4:00 PM BIDS DUE BY: December 13, 2018: 2:00 PM Sharp! Hawthorne School District 13021 S. Yukon Ave. Hawthorne, CA 90250 RFP DOCUMENTS AVAILABLE: http://www.hawthorne.k12.ca.us/bids NOTICE IS HEREBY GIVEN that the Hawthorne District of Los Angeles County, California, acting by and through its Governing Board, hereinafter referred to as the “Owner” or “District”, will receive prior to the above stated time and date sealed bids for the award of a Contract for the following: Bid No. M18-19-3 Roofing Projects. All bids shall be made and presented only on the forms presented by the Owner. Bids shall be received in the Office of the Hawthorne School District, Purchasing Department, at 13021 S. Yukon Ave., Hawthorne, California 90250, and shall be opened and publicly read aloud at the above state time and place. Any bids received after the time specified above or after any extensions due to material changes shall be returned unopened. The Contract Time will be coordinated with the awarded Contractor(s), and referenced in the Notice to Proceed. Work will be done in phases, during the spring, summer, and the winter breaks. CONTRACTOR should consult the General Conditions, Supplementary Conditions, and General Requirements regarding Milestones and Liquidated Damages. There will be a mandatory Pre-Bid Conference and Job walk on November 28, 2018, 8:30 AM Sharp! Any Contractor bidding on the Project who fails to attend the entire mandatory job walk and conference will be deemed as non-responsive bidder and will have its bid returned unopened. Job walk will immediately follow after Bidder’s conference. Please allocate extra time due to the parking restrictions in the area. Each bidder shall be a licensed contractor pursuant to the California Business and Professions Code, and be licensed to perform the work called for in the Contract Documents. The successful bidder must possess a valid and active Class C39 License at the time of bid and throughout the duration of this Contract. The Contractor’s California State License number shall be clearly stated on the bidder’s proposal Subcontractors shall be licensed pursuant to California law for the trades necessary to perform the Work called for in the Contract Documents. Each bid must strictly conform with and be responsive to the Contract Documents as defined in the General Conditions. In accordance with California Public Contract Code Section 22300, the Owner will permit the substitution of securities for any moneys withheld by the Owner to ensure performance under the Contract. Prevailing wages are applicable to the Project. These per diem rates, including holiday and overtime work, as well as employer payments for health and welfare, pension, vacation, and similar purposes, are available from the Director of the Department of Industrial Relations. Pursuant to California Labor Code Sections 1720 et seq., it shall be mandatory upon the Contractor to whom the Contract is awarded, and upon any subcontractor under such Contractor, to pay not less than the said specified rates to all workers employed by them in the execution of the Contract. A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in the Labor Code, unless currently registered and qualified to perform public work pursuant to Labor Code section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded. The Contractor and all subcontractors shall furnish certified payroll records as required pursuant Labor Code section 1776 directly to the Labor Commissioner in accordance with Labor Code section 1771.4 on at least on a monthly basis (or more frequently if required by the District or the Labor Commissioner) and in a format prescribed by the Labor Commissioner. Monitoring and enforcement of the prevailing wage laws and related requirements will be performed by the Labor Commissioner/ Department of Labor Standards Enforcement (DLSE). Separate payment and performance bonds, each in an amount equal to 100% of the total Contract amount issued by a California admitted surety as defined in California Code of Civil Procedure Section 995.120, are required, and shall be provided to the Owner prior to execution of the Contract and shall be in the form set forth in the Contract Documents. Where applicable (including projects receiving funding under the State School Facilities Program), bidders must meet the requirements set forth in Public Contract Code Section 10115 et seq., Military and Veterans Code Section 999 et seq. and California Code of Regulations, Title 2, Section 1896.60 et seq. regarding Disabled Veteran Business Enterprise (“DVBE”) Programs. Bid Security. Each Bid Proposal shall be accompanied by Bid Security in an amount TEN PERCENT (10%) OF THE TOTAL BID AMOUNT. Failure of any Bid Proposal to be accompanied by Bid Security in the form and in the amount required shall render such Bid Proposal to be non-responsive and rejected by the District. No Withdrawal of Bid Proposals. No Bidder shall withdraw its Bid Proposal for a period of ninety (90) days after the award of the Contract by the District’s Board of Education. During this time, all Bidders shall guarantee prices quoted in their respective Bid Proposals. Substitute Security. In accordance with the provisions of California Public Contract Code §22300, substitution of eligible and equivalent securities for any monies withheld by the District to ensure the Contractor’s performance under the Contract will be permitted at the request and expense of the Contractor. The foregoing notwithstanding, the Bidder to whom the Contract is awarded shall have thirty (30) days following action by the District’s Board of Education to award the Contract to such Bidder to submit its written request to the District to permit the substitution of securities for retention. The failure of the Bidder to make such written request to the District within said thirty (30) day period shall be deemed a waiver of the Bidder’s rights under California Public Contract Code §22300. Waiver of Irregularities. The District reserves the right to reject any or all Bid Proposals or to waive any irregularities or informalities in any Bid Proposal or in the bidding. Award of the Contract. The Contract for the Work, if awarded, will be by action of the District’s Board of Trustees to the responsible Bidder submitting the lowest responsive Bid Proposal. Inquiries and Clarifications. The Bidder is advised that all inquiries and clarifications about the Bid Documents, Drawings, Specifications, etc., shall be submitted to the District in writing at least seven (8) days before the bid opening date. The District will respond at its earliest possible opportunity. Verbal communication by either party with regard to this matter is invalid. Inquiries shall be sent in writing to Aneska Ines Kekula, Purchasing Director, at ikekula@hawthorne.k12.ca.us by December 4, 2018, at 4:00 PM It is each bidder’s sole responsibility to ensure its bid is timely delivered and received at the location designated as specified above. Any bid received at the designated location after the scheduled closing time for receipt of bids shall be returned to the bidder unopened. Aneska Ines Kekula Purchasing Director HAWTHORNE SCHOOL DISTRICT Los Angeles County, State of California FOR: The Board of Trustees Hawthorne Press Tribune Pub. 11/15, 11/22/18 HH-26247 NOTICE OF PETITION TO ADMINISTER ESTATE OF: XAVIER WILLIS AKA XAVIER ANTHONY VAN WILLIS CASE NO. 18STPB10442 To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the WILL or estate, or both of XAVIER WILLIS AKA XAVIER ANTHONY VAN WILLIS. A PETITION FOR PROBATE has been filed by DANYELLE WHITE in the Superior Court of California, County of LOS ANGELES. THE PETITION FOR PROBATE requests that DANYELLE WHITE be appointed as personal representative to administer the estate of the decedent. THE PETITION requests authority to administer the estate under the Independent Administration of Estates Act with limited authority. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority. A HEARING on the petition will be held in this court as follows: 12/10/18 at 8:30AM in Dept. 11 located at 111 N. HILL ST., LOS ANGELES, CA 90012 IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law. YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk. Attorney for Petitioner TAMSEN REINHEIMER - SBN 234257 MORTENSEN & REINHEIMER, PC 2855 MICHELLE DRIVE, SUITE 120 IRVINE CA 92606 11/15, 11/22, 11/29/18 CNS-3194653# Inglewood Daily News Pub. 11/15, 11/22, 11/29/18 HI-26248 NOTICE OF PUBLIC HEARING CONDITIONAL USE PERMIT 2018CU01 PUBLIC NOTICE is hereby given that the Planning Commission of the City of Hawthorne will hold a public hearing to consider the following matter: CONDITIONAL USE PERMIT NO. 2018CU01: A request to approve the construction of a new 119 room hotel. PROJECT LOCATION: 11519 Acacia Avenue - City of Hawthorne, Los Angeles County, State of California MEETING DETAILS: Day: Wednesday Date: December 5, 2018 Time: 6:00 PM Place: City Council Chambers 4455 West 126th Street Hawthorne, CA 90250 Those interested in this item may appear at the meeting and submit oral or written comments. Written information pertaining to this item must be submitted to the Planning and Community Development Department prior to 5:30 PM November 30, 2018, at 4455 West 126th Street, Hawthorne, California 90250 or emailed to Cpalmer@cityofhawthorne.org. For additional information, you may contact Christopher Palmer at (310) 349-2973 or at the email noted above. ENVIRONMENTAL REVIEW: Conditional Use Permit No. 2018CU01 is Categorically Exempt per Section 15332, Class 1, (In-Fill Development Projects) of the California Environmental Quality Act (CEQA), the application is categorically exempt from the requirements for preparation of a Negative Declaration or Environmental Impact Report. PLEASE NOTE that pursuant to Government Code Section 65009: In an action or proceeding to attack, review, set aside, void, or annul a finding, determination or decision of the Planning Commission or City Council, the issues raised shall be limited to those raised at the public hearing in this notice or in written correspondence delivered to the Planning Commission or City Council at or prior to the public hearing. Hawthorne Press Tribune Pub. 11/22/18 HH-26257 NOTICE OF PUBLIC HEARING CONDITIONAL USE PERMIT 2018CU07 PUBLIC NOTICE is hereby given that the Planning Commission of the City of Hawthorne will hold a public hearing to consider the following matter: CONDITIONAL USE PERMIT NO. 2018CU07: A request to approve the off-site sell of alcohol in conjunction with other retail items at a new retail facility. PROJECT LOCATION: 3670 Imperial Highway - City of Hawthorne, Los Angeles County, State of California MEETING DETAILS: Day: Wednesday Date: December 5, 2018 Time: 6:00 PM Place: City Council Chambers 4455 West 126th Street Hawthorne, CA 90250 Those interested in this item may appear at the meeting and submit oral or written comments. Written information pertaining to this item must be submitted to the Planning and Community Development Department prior to 5:30 PM November 30, 2018, at 4455 West 126th Street, Hawthorne, California 90250 or emailed to Cpalmer@cityofhawthorne.org. For additional information, you may contact Christopher Palmer at (310) 349-2973 or at the email noted above. ENVIRONMENTAL REVIEW: Conditional Use Permit No. 2018CU07 is Categorically Exempt per Section 15301, Class 1, consisting of the operation of an existing facility involving negligible or no expansion of the existing use. The restaurant is establishing within a portion of an existing building and is adding on-site sales of beer and wine with no expansion of the existing structure. PLEASE NOTE that pursuant to Government Code Section 65009: In an action or proceeding to attack, review, set aside, void, or annul a finding, determination or decision of the Planning Commission or City Council, the issues raised shall be limited to those raised at the public hearing in this notice or in written correspondence delivered to the Planning Commission or City Council at or prior to the public hearing. Hawthorne Press Tribune Pub. 11/22/18 HH-26258 LIEN SALE: 2009 MERCEDES VIN: WDDGF54X09R052647 DATE OF SALE: 10:00 A.M. 12/10/18 ADDRESS: 2025 W. FLORENCE AVE. LOS ANGELES, CA 90047 INGLEWOOD DAILY NEWS: 11/22/18 HI-26259 LIEN SALE: 2006 INFINITI VIN: JNKCV54EX6M714784 DATE OF SALE: 10:00 A.M. 12/10/18 ADDRESS: 10827 WRIGHT FD SOUTH GATE, CA 90280 INGLEWOOD DAILY NEWS: 11/22/18 HI-26260
Hawthorne_112218_FNL_lorez
To see the actual publication please follow the link above